The Novation Agreement for Shipbuilding Contracts is an agreement between the parties to novate the shipbuilding contract from the original buyers to the new buyers on terms set out in the agreement. The latest edition of this contract is the Novation Agreement for Shipbuilding Contracts, issued in 2016.
Copyright in the Novation Agreement for Shipbuilding Contracts is held by BIMCO.
Sample copy of Novation Agreement for Shipbuilding ContractsDownload now
Novation of a shipbuilding contract can be expected to include provisions reflecting case-specific party needs and requirements. The new standard agreement addresses core underlying issues which are common to all shipbuilding novation agreements. It cannot cover the many and variable situations that might be encountered or required by parties during individual negotiations.
These notes are intended to provide an insight into the reasoning behind the key provisions of the Novation Agreement for Shipbuilding Contracts. However, users are recommended to seek advice in respect of issues that are not covered, are specific to their contractual arrangements or require specialist legal guidance.
An important issue concerns title to the ship. Under shipbuilding contracts, title normally passes to the purchaser on delivery of the ship. However, this is not always the position and in some cases title passes during construction. The position should always be confirmed.
It is also important to check the new contracting party’s liabilities, responsibilities and payment obligations for previously ordered supplies and equipment either installed or ready to be installed on the ship. Liability for the cost of bunkers and lube oils used during the construction period should also be established.
The agreement is divided into two sections. The covering box layout is for the insertion of variable information including the names of the parties, the ship and underlying shipbuilding contract details followed by the terms and conditions of the novation.
Details of the contracting builders are to be entered in Box 2. However, as this might be a trading house with actual construction undertaken elsewhere, shipyard details must be inserted in Box 5. In order to avoid the complexity of enumerating all documentation making up the Shipbuilding Contract, only the date of the contract is required to be entered in Box 7 but a cross-reference in the Background section defines documentation as “comprising the entire Shipbuilding Contract”. Further information to be entered includes: Box 9, Builders’ Guarantor, Box 10 Original Buyers’ Guarantor, Box 11 New Buyers’ Guarantor and Box 12 for details of Instalments Paid (by the Original Buyers).
This states the parties’ agreement to novate the Shipbuilding Contract from the Original Buyers (identified in Box 3) to the New Buyers (identified in Box 4) on terms set out in the agreement. In order to ensure consistency, it is expressly provided that terms used in the Novation Agreement shall have the same meaning as terms in the underlying Shipbuilding Contract.
The changeover of contracting party takes effect from the “Effective Time” agreed and entered in Box 8.
In order to eliminate scope for later disputes about enforcement or recovery of claims between the Original Buyers and the Builders, subclauses (d) and (e) expressly provide that the New Buyers assume all rights, responsibilities and obligations for all matters arising as from the date the original shipbuilding contract was signed.
Subclause (b) given that the New Buyers accept all liability from the date of the contract (the date stated in Box 7), it follows that guarantees in place for the pre-novated shipbuilding contract are no longer required. Subject to fulfilment of subclause (a), the Builders’ and Original Buyers’ guarantors will be released from their obligations under the pre-novated shipbuilding contract.
Subclause (b) the Original Buyers and Builders warrant that, unless provided for in the Novation Agreement, there have been no contractual changes and confirm that there has been no breach of, or dispute between them about, the terms and conditions of the shipbuilding contract. The Builders are also required to warrant that there are no notified delays or permitted adjustments to the delivery date or price; a schedule of agreed adjustments must be provided; and the Original Buyers must warrant details of instalments paid in accordance with Box 12.
Subclause (c) the Original Buyers warrant that, as at the Effective Time, their interests have not been assigned to any other party. Care is needed on this point as it is possible that in order to secure their financing arrangements, the Original Buyers will have assigned their interests in the Shipbuilding Contract to a bank or financial institution. In order to be able to comply with this warranty, it is important that such rights are re-assigned back to the Original Buyers. Specialist advice may be required.
Subclause (d) requires each party to take all necessary action to give effect to the Novation Agreement once it has been concluded. Any resulting costs will lie where they fall.
Disputes under a novation agreement might involve all three contracting parties. Additional wording has therefore been included to provide a mechanism for starting multi-party disputes. The procedures apply where all three parties are involved in a dispute from the outset but are not designed to accommodate a third party joining an extant arbitration at a later stage. If the situation should arise, it can be dealt with on a case by case basis with the third party possibly starting a separate arbitration against either or both of the other parties. The references might then, by agreement, be consolidated, heard concurrently or restarted as a multi-party arbitration.
The modifications mean that the clause is not the standard version and “BIMCO” does not therefore appear in the heading.
Anna Wollin (BIMCO), Chris Kidd (Ince and Co) and Donald Chard (Arbitrator and BIMCO consultant) provide an overview of the Standard Novation Agreements.
The one-stop digital shop for all the standard maritime contracts and clauses you’ll ever need.
BIMCO is to develop an electronic bill of lading standard for the dry and liquid bulk sectors as a key component of a global initiative to accelerate trade digitalisation.
Documentary Committee Chairman Francis Sarre of CMB has, after six years in the driver’s seat, passed over the reins of BIMCO’s contracts and clauses approval body to Nick Fell of BW Group. Fell takes over as Chairman at a time when the industry needs strong contractual solutions, not least due to the COVID-19 pandemic.
BIMCO’s documentary experts have begun preparing charter party clauses to assist owners and charterers comply with complex new carbon regulations due to come into force in 2023.
BIMCO has published a charter party clause promoting the use of the IMO’s data model framework. The publication is an extension of BIMCO’s strategic objective to encourage greater efficiency and harmonisation in the ship-shore interface.
Although the container ship “Ever Given” was fortunately freed after less than a week blocking the Suez Canal, the consequences for owners and operators due to the delays caused may last for several weeks or even months.
BIMCO's Holiday Calendar covers general holidays in over 150 countries, plus local holidays and working hours in more than 680 ports around the world.
Access information on national, regional or port tariffs, taxes and charges.
For general guidance and information on cargo-related queries.